These Terms and Conditions govern your use of the Glass Partition Company website and any enquiries made through glasspartitioncompany.co.uk.
By using this website, you agree to these Terms and Conditions. If you do not agree with these terms, you should stop using the website.
1. About Glass Partition Company
Glass Partition Company provides glass partition design, supply and installation services for commercial properties, offices, businesses and other premises across the UK.
These Terms and Conditions apply to the use of our website. Specific quotations, proposals, orders and contracts may be subject to additional terms provided before work begins.
2. Using Our Website
You may use our website to:
Learn about our glass partition services
View information about glass partition systems and installations
Make an enquiry
Request information or a quotation
Contact us about a potential project
You must use this website lawfully and must not use it in a way that could damage the website, interfere with its operation or prevent other people from using it.
You must not attempt to gain unauthorised access to the website, its server or any systems connected to it.
3. Website Information
We aim to provide clear and accurate information about our services. However, website content provides general information and does not constitute a binding quotation, specification or contractual commitment.
Glass partition systems, specifications, finishes, dimensions, acoustic performance, fire performance, availability and installation requirements can vary between projects.
We may update, remove or change website content without notice because our products, services and technical specifications may change.
You should not rely solely on general website information when making decisions about a specific project.
4. Enquiries
You can contact us through the website to discuss a glass partition project or request further information.
Submitting an enquiry does not create a contract between you and Glass Partition Company.
Information provided during an initial enquiry may be used to assess your requirements and determine whether we can assist with your project.
You are responsible for providing accurate information about your project, property and requirements because inaccurate or incomplete information may affect any quotation or advice we provide.
5. Quotations
Any quotation we provide will be based on the information available to us at the time.
A quotation may take account of factors including:
Project dimensions
Glass specifications
Partition system requirements
Door requirements
Hardware and finishes
Access to the property
Installation conditions
Delivery requirements
Site location
Programme requirements
Additional works requested
A quotation does not create a binding contract unless it has been accepted in accordance with the terms stated in the quotation or other contractual documentation.
Unless expressly stated otherwise, prices or example costs shown on our website should be treated as indicative only.
6. Site Surveys and Measurements
Some projects may require a site survey before we can confirm specifications, measurements or final pricing.
Measurements supplied by a customer or third party remain their responsibility unless we have agreed to carry out our own survey and accept responsibility for those measurements.
Site conditions discovered after a quotation has been issued may affect the specification, installation method, timescale or price.
Where additional work becomes necessary because of previously undisclosed or unforeseen site conditions, we will discuss the implications with the customer before carrying out material additional work where reasonably practicable.
7. Orders and Contracts
A contract for the supply or installation of products or services will only arise when an order has been accepted by us in accordance with the applicable quotation, proposal, order confirmation or other agreed contractual terms.
The contract may include additional terms covering matters such as:
Price
Payment
Deposits
Specifications
Delivery
Installation
Programme dates
Variations
Cancellation
Warranties
Where specific contractual terms conflict with these general website Terms and Conditions, the specific terms agreed for the project will take precedence in relation to that project.
8. Prices and Payment
Prices for glass partition projects depend on the individual requirements of each installation.
Any payment terms applicable to a project will be stated in the relevant quotation, invoice, order confirmation or contract.
Customers must make payments in accordance with the agreed payment terms.
Failure to make payment when due may result in work, delivery or installation being delayed or suspended where permitted by the applicable contract and law.
9. Project Timescales
Any timescales provided before or during a project are based on the information available at that time.
We will take reasonable steps to meet agreed project dates. However, delivery and installation dates can be affected by circumstances outside our reasonable control.
These circumstances may include:
Supplier delays
Manufacturing delays
Transport disruption
Site access restrictions
Changes requested by the customer
Delays caused by other contractors
Unforeseen site conditions
Adverse weather
Events outside our reasonable control
We will communicate material delays where reasonably practicable.
10. Site Access and Preparation
Where installation services are provided, the customer is responsible for ensuring that we have reasonable and safe access to the installation area at the agreed time.
Unless otherwise agreed, the site should be sufficiently prepared for the work to take place.
Delays caused by inadequate access, unsafe conditions, unfinished preparatory work or interference from other works may affect the installation programme and could result in additional costs.
11. Variations to a Project
Changes requested after a quotation or order has been accepted may affect the price, specification and completion date.
We may provide a revised quotation or variation price where additional or different work is requested.
We are not required to carry out additional work that falls outside the agreed scope unless we agree to the variation.
12. Products, Materials and Finishes
Images and descriptions on our website provide a general representation of the products and finishes available.
Colours, finishes, glass appearance and other visual characteristics may differ slightly from photographs or digital representations because screens, lighting conditions, manufacturing processes and natural variations can affect appearance.
Specific requirements should be confirmed as part of the quotation and ordering process.
13. Building Regulations and Project Requirements
Different projects may be subject to different building regulations, fire safety requirements, acoustic requirements, planning considerations and other technical standards.
The suitability of a particular glass partition system depends on the requirements and circumstances of the individual project.
Customers, designers, contractors and other responsible parties should ensure that relevant project requirements are identified before products or services are ordered.
Where we expressly agree to provide a product or system to a particular stated specification, that requirement should be recorded in the applicable quotation or contract.
14. Intellectual Property
Unless stated otherwise, the content of this website belongs to Glass Partition Company or is used with permission.
This content may include:
Text
Images
Photographs
Graphics
Branding
Logos
Website design
Documents
Illustrations
You may view and use the website for personal or legitimate business purposes.
You must not reproduce, republish, distribute, sell or commercially exploit substantial parts of our website content without permission unless the law allows you to do so.
15. Website Availability
We aim to keep the website available and functioning correctly. However, we do not guarantee uninterrupted access.
We may temporarily restrict or suspend access for maintenance, security, technical or operational reasons.
We are not responsible for losses caused solely by temporary website unavailability where this is outside our reasonable control.
16. External Links
Our website may contain links to websites operated by third parties.
We provide external links for convenience or additional information. We do not control third-party websites and are not responsible for their content, availability, security or privacy practices.
A link to another website does not necessarily mean that we endorse that website, business, product or service.
17. Liability
Nothing in these Terms and Conditions excludes or limits liability where doing so would be unlawful.
We do not exclude liability for death or personal injury caused by negligence, fraud, fraudulent misrepresentation or any other liability that cannot legally be excluded.
Website content provides general information. We are not responsible for losses resulting from reliance on general website content where project-specific professional or technical assessment was reasonably required.
Any liability relating to a specific project may also be governed by the quotation, order confirmation, contract or other terms agreed for that project.
18. Viruses and Website Security
We take reasonable steps to maintain the security of our website. However, we cannot guarantee that the website will always be completely secure or free from viruses or other harmful components.
You are responsible for protecting your own devices, systems and data when accessing websites.
You must not knowingly introduce viruses, malicious code or other harmful material to our website.
19. Privacy and Personal Information
We process personal information in accordance with our Privacy Policy.
Our Privacy Policy explains what personal information we collect, why we collect it, how we use it and your rights under UK data protection law.
You should read our Privacy Policy alongside these Terms and Conditions.
20. Changes to These Terms
We may update these Terms and Conditions when our website, services, business practices or legal requirements change.
The latest version will be published on this website. The date at the top of this page shows when these Terms and Conditions were last updated.
Changes will apply to website use from the date the revised terms are published. Changes will not retrospectively alter an existing contract unless permitted by that contract or agreed by the parties.
21. Severability
If any part of these Terms and Conditions is found to be unlawful, invalid or unenforceable, the remaining provisions will continue to apply.
22. Governing Law
These Terms and Conditions are governed by the laws of England and Wales.
Any dispute relating to the use of this website will be subject to the jurisdiction of the courts of England and Wales, subject to any mandatory legal rights that apply.
23. Contact
If you have questions about these Terms and Conditions, our services or a quotation, please contact Glass Partition Company using the contact details provided on our website.